Terms & Conditions
The following terms and conditions apply to all website development / design services provided by GM Creative Art to the Client.
Agreement means the Project Proposal, Terms and Conditions and any other attached documents.
Project means the scope and purpose of the Client’s identified usage of the work product as described in the Project Proposal.
Services means all services and the work product to be provided to Client by Designer as described and otherwise further defined in the Project Proposal.
Final Deliverables means the final versions of Deliverables provided by Designer and accepted by Client.
Deliverables means the services and work product specified in the Project Proposal to be delivered by Designer to Client.
Client Content means all materials, writing, images or other creative content provided by Client used in preparing or creating the Deliverables.
Third Party Materials means proprietary third party materials which are incorporated into the Final Deliverables, including without limitation to stock photography, illustration and/or video material.
Designer Tools means all design tools developed and/or used by Designer in performing the Services, including pre-existing and newly developed software including source code, Web authoring tools, type fonts, and application tools, together with any other software, or other inventions whether or not patentable, and general non-copyrightable concepts such as website design, architecture, layout, navigational and functional elements.
It is not necessary for any Client to have signed an acceptance of these terms and conditions for them to apply. If a Client accepts a quote then the Client will be deemed to have satisfied themselves as to the terms applying and have accepted these terms and conditions in full.
Please read these terms and conditions carefully. Any purchase or use of our services implies that you have read and accepted our terms and conditions.
Designer shall perform the services listed the Scope of Work according to the Work Plan and Milestones schedule.
PROPOSAL (aka Scope of Work)
The terms of this Agreement expires 14 days after being submitted to Client. If this Agreement expires, Designer may modify the Agreement and resubmit it to Client.
Charges for services to be provided by GM Creative Art are defined in the project quotation that the Client receives via e-mail or agrees to by adding the product to cart. Quotations are valid for a period of three (3) days. GM Creative Art reserves the right to alter or decline to provide a quotation after expiry of the three (3) days.
Unless agreed otherwise with the Client, all website design services require an advance payment of a minimum of fourty (40) percent of the project quotation total before the work is supplied to the Client for review. A second charge and final payment of sixty (60) percent is required after the development stage and upon completion of the work, prior to upload to the server or release of materials.
The remaining sixty (60) percent shall become due when the work is completed to your reasonable satisfaction but subject to the terms of the “approval of work” and “rejected work” clauses. We reserve the right not to commence any work until the first deposit has been paid in full.
The sixty (60) percent deposit is only refundable if we have not fulfilled our obligations to deliver the work required under the agreement. The deposit is not refundable if the development work has been started and you terminate the contract through no fault of ours.
Payment for services is due by bank transfer. Bank details will be made available on invoices.
Fees: Client agrees to pay Designer the fees listed in the Project Proposal, including all taxes.
Expenses: Client will pay Designer expenses, including but not limited to: (a) Incidental and out-of-pocket expenses; (b) Milage reimbursement, other than normal commuting (c) Travel expenses, other than normal commuting, but including airfare and rental vehicles, with client approval.
Additional Costs: Pricing in the Project Proposal includes only Designer fees. Any other costs, such as hosting, art licensing or photography, will be billed to Client.
Hosting Final Deliverables: Designer will host the Final Deliverables on Designers web space while the Project is under construction. If the Final Deliverables are not completed by the completion date listed in the Project Proposal, and the delay is not caused by Designer, Client agrees to pay Designer 100 EUR per month for hosting until the Final Deliverables are moved to Clients server.
Payment Schedule: Payment is due when Designer completes each milestone as listed in the Work Plan and Milestones schedule, and Client accepts the Deliverables for that milestone.
Invoices: All invoices are payable within three (3) working days of receipt. Invoices shall list any expenses and additional costs as separate items.
Late Fee: A monthly service fee of ten (10) percent, or the maximum allowed by law, is payable on all overdue balances.
Crediting Late Payments: Payments will be credited to late payments first, then to unpaid balances.
Collection Expenses: Client shall pay all collection or legal fees caused by late payments.
Withholding Delivery: Designer may withhold delivery and transfer of ownership of any current work if accounts are not current or overdue invoices are not paid in full.
Withholding License: All grants of any license to use or transfer ownership of any intellectual property rights under this Agreement are conditioned on full payment, including all outstanding Additional Costs, Expenses, Fees, or any other charges.
Client agrees to reimburse GM Creative Art for any requested expenses which do not form part of our proposal including but not limited to the purchase of templates, third party software, stock photographs, fonts, domain name registration, web hosting or comparable expenses.
CHANGES TO PROJECT SCOPE
Change Request: If Client wants to change the Scope of Work after acceptance of this Agreement, Client shall send Designer a written Change Order describing the requested changes in detail. Within fourteen (14) days of receiving a Change Order, Designer will respond with a statement proposing designers availability, additional fees, changes to delivery dates, and any modification to the Terms and Conditions. Designer will evaluate each Change Order at its standard rate and charges.
Major Change: If Client requests are at or near 20% percent of the time required to produce Deliverables, or the value of the Scope of Services, Designer shall be entitled to submit a new and separate Proposal to Client for written approval. Designer shall not begin work on the revised services until he receives a fully signed revised proposal and any additional fees.
Minor Change: If Client requests are not Major Changes, Client will be billed on a time and materials basis at Designers hourly rate of 60 EUR per hour. Such charges shall be in addition to all other amount payable under this Agreement, despite any maximum budget, contract price or final price identified. Designer may extend or modify any delivery schedule or deadlines in the Agreement as may be required by such changes.
Acceptance/Rejection: Client will have seven (7) days to respond in writing accepting or rejecting the new proposal. If Client rejects the proposal, Designer will not be obligated to perform any services beyond those in the original Agreement.
EVALUATION AND ACCEPTANCE
Testing: Designer will test and correct Deliverables using commercially reasonable efforts before providing Deliverables to Client.
Approval Periods: Client shall, within 7 business days after receiving each Deliverable, notify Designer in writing of any failure to comply with the specification of the Project Proposal or of any other objections, corrections or changes required. Designer shall, within 14 business days of receiving Clients notification, correct and submit a revised Deliverable to Client. Client shall, within 7 business days of receiving a revised Deliverable, either approve the corrected version or make further changes and send the revised Deliverable to the Designer, allowing him 14 business days to complete the task. If after 3 corrections by Designer, Client finds the Deliverables are not acceptable, Client may terminate this agreement subject to the termination clauses of this Agreement. If Client fails to provide approval or comments during any approval period, those Deliverables will be considered approved and accepted. Any of the work which has not been reported in writing to us as unsatisfactory within the 7-day review period will be deemed to have been approved. Once approved, or deemed approved, work cannot subsequently be rejected and the contract will be deemed to have been completed and the remaining sixty (60) percent balance of the project price will become due. All objections, corrections and changes shall be subject to the terms and conditions of this Agreement.
Rejection of work
If you reject any of our work within the 7-day review period, or not approve subsequent work performed by us to remedy any points recorded as being unsatisfactory, and we, acting reasonably, consider that you have been unreasonable in any rejection of the work, we can elect to treat this contract as at an end and take measures to recover payment for the completed work. All objections, corrections and changes required after the seven (7) days review period will not be taken into consideration, as the Deliverables will be considered approved and the Client will be billed for the completed work at that specific development stage.
Designer Delays: Designer shall use all reasonable efforts to meet the Work Plan and Milestones delivery schedule. Designer may extend the due date for any Deliverable by giving written notice to Client. The total of all extensions shall not exceed 21 days.
Client Delays: Client shall use all reasonable efforts to provide needed information, materials and approvals. Any delay by Client will result in a day-for-day extension of the due date for all Deliverables.
General Delays: Any delay caused be conditions beyond the reasonable control of the parties shall not be considered a breach and will result in a day-for-day extension any performance due. Each party shall use reasonable efforts to notify the other party, in writing, of a delay. Conditions beyond the reasonable control of the parties include, but are not limited to, natural disasters, acts of government after the date of agreement, power failure, fire, flood, acts of God, labor disputes, riots, acts of war, terrorism and epidemics.
Client acknowledges that he is responsible for performing the following in a reasonable and timely manner: (a) Provide the Designer Content in a form suitable for use in the Deliverables without further preparation by Designer, unless otherwise specified in the Project Proposal; (b) Proofread all Deliverables. Client will be charged for correcting errors after the acceptance of any Deliverable; (c) Make decisions regarding other parties.
SUPPLY OF MATERIALS
In order to remain efficient we must ensure that work we have programmed is carried out at the scheduled time. On occasions we may have to reject offers for other work and enquiries to ensure that your work is completed at the time arranged.
This is why we ask that you provide all the required information in advance. Such information may include, but are not limited to, photographs, written copy, logos and other printed material. Where there is any delay in supplying these materials to us which leads to a delay in the completion of work, we have the right to extend any previously agreed deadlines by a reasonable amount. On any occasion where progress cannot be made with your website because we have not been given the required information in the agreed time frame, and we are delayed as result, we reserve the right to impose a surcharge of up to 25%. If your project involves Search Engine Optimization we need the text content for your site in advance so that the SEO can be planned and completed efficiently.
If you agree to provide us with the required information and subsequently fail to do within one week of project commencement we reserve the right to close the project and the balance remaining becomes payable immediately. Simply put, all the above condition says is do not give us the go ahead to start until you are ready to do so.
NOTE: Text content should be delivered in ASCII format as a Microsoft Word, PDF, email (or similar) document with the pages in the supplied document representing the content of the relevant pages on your website. These pages should have the same titles as the agreed website pages. The photographs and other graphics will be provided physically in high quality print suitable for scanning or electronically in .gif, .jpeg, .png or .tiff format. Although every reasonable attempt shall be made by GM Creative Art to return to the Client any images or printed material provided for use in creation of the Client's website, such return cannot be guaranteed. Contact us if you need clarification on this.
Using our content management system you are able to keep your content up to date yourself.
A link to GM Creative Art will appear in either small type or by a small graphic at the bottom of the Client's website. If a graphic is used, it will be designed to fit in with the overall site design. If a client requests that the design credit be removed, a nominal fee of 10% of the total development charges will be applied. The Client also agrees that the website developed for the Client may be presented in GM Creative Art’s portfolio.
ACCREDITATION AND PROMOTION
Accreditation: Designer shall be entitled to place accreditation, as a hyperlink or otherwise, in the form, size and location as incorporated by Designer in the Deliverables on each page of the Final Deliverables.
Promotion: Designer retains the right to reproduce, publish and display the Deliverables in Designer’s portfolios and websites, in galleries, design periodicals and other media or exhibits for the purposes of recognition of creative excellence or professional advancement, and to be credited with authorship of the Deliverables in connection with such uses. Promotional Approval: Either party, subject to the other’s reasonable approval, may describe its role in the Project on its website and in other promotional and marketing materials, and, if not expressly objected to, include a link to the other party’s website.
Client’s "Confidential Information" includes information that Designer should reasonably believe to be confidential. Designer's "Confidential Information" includes the source code of any Designer Tools. All material considered confidential by either party shall be designated as confidential. Confidential Information shall not be disclosed to third parties and shall only used as needed to perform this Agreement. Confidential Information shall not include any information that is already known by the recipient, becomes publicly known through no fault of the recipient, or is received from a third party without a restriction on disclosure
RELATIONSHIP OF THE PARTIES
Independent Contractor: Designer is an independent contractor. Designer shall determine, in its sole discretion, the manner and means by which the Services are accomplished. No agency, partnership, joint venture, or employee-employer relationship is intended or created by this Agreement. Neither party is authorized to act as agent or bind the other party except as expressly stated in this Agreement. Designer and the work product or Deliverables prepared by Designer shall not be deemed a work for hire as defined under Copyright Law. All rights granted to Client are contractual in nature and are expressly defined by this Agreement. Design Agents. Designer shall be allowed to use third party’s as independent contractors in connection with the Services (“Design Agents”). Designer shall remain fully responsible for Design Agents’ compliance with this Agreement.
No Exclusivity: This Agreement does not create an exclusive relationship between the parties. Client is free to engage others to perform services of the same or similar nature to those provided by Designer, and Designer shall be entitled to offer and provide design services to others, solicit other clients and otherwise advertise the services offered by Designer.
We reserve the right to subcontract any services that we have agreed to perform for you as we see fit.
We (and any subcontractors we engage) agree that we will not at any time disclose any of your confidential information to any third party.
REPRESENTATIONS AND WARRANTIES
By Client: Client represents and warrants to Designer that: (a) To the best of Client’s knowledge, use of the Client Content does not infringe the rights of any third party; (b) Client shall comply with the terms and conditions of any licensing agreements which govern the use of Third Party Materials; (c) Client will obtain all necessary and appropriate rights and licenses to grant license to Designer to use Third Party Materials.
By Designer: Designer represents and warranty to Client that: (a) Designer will provide the Services identified in the Agreement in a professional and workmanlike manner; (b) Designer shall secure all necessary rights, title, and interest in and to the Final Deliverables, including Designer Tools, sufficient for Designer to grant the intellectual property rights provided in this Agreement; (c) To the best of Designer’s knowledge, the Deliverables will not violate the rights of any third parties; (d) If Client or third parties modify the Deliverables or use the Deliverables outside of the scope or purpose of this Agreement, all representations and warranties of Designer shall be void.
EXCEPT FOR THE EXPRESS REPRESENTATIONS AND WARRANTIES STATED IN THIS AGREEMENT, DESIGNER MAKES NO WARRANTIES WHATSOEVER. DESIGNER EXPLICITLY DISCLAIMS ANY OTHER WARRANTIES OF ANY KIND, EITHER EXPRESS OR IMPLIED, INCLUDING BUT NOT LIMITED TO WARRANTIES OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE OR COMPLIANCE WITH LAWS OR GOVERNMENT RULES OR REGULATIONS APPLICABLE TO THE PROJECT.
OWNERSHIP OF INTELLECTUAL PROPERTY RIGHTS
Client must obtain all necessary permissions and authorities in respect of the use of all copy, graphic images, registered company logos, names and trademarks, or any other material that he supplies to us to include in the website or web applications.
Client must indemnify us and hold us harmless from any claims or legal actions related to the content of the website.
INDEMNIFICATION AND LIABILITY
By Client: Client shall indemnify Designer from any and all damages, liabilities, costs, losses, expenses or attorney fees arising out of any claim, demand, or action by a third party arising out of any breach of Client’s responsibilities or obligations, representations or warranties under this Agreement. Designer shall promptly notify Client in writing of any third party claim or suit. Client shall have the right to fully control the defense and any settlement of such claim or suit.
By Developer: In the case of a third party lawsuit or proceeding based on a claim that Deliverables breach the third party’s intellectual property rights, and it is determined that such infringement has occurred, Designer may at its own expense, replace any infringing content with non-infringing content.
Limitation of Liability. THE SERVICES AND THE WORK PRODUCT OF DESIGNER ARE SOLD “AS IS.” IN ALL CIRCUMSTANCES, THE MAXIMUM LIABILITY OF DESIGNER, ITS DIRECTORS, OFFICERS, EMPLOYEES, DESIGN AGENTS AND AFFILIATES (“DESIGNER PARTIES”), TO CLIENT FOR DAMAGES FOR ANY AND ALL CAUSES WHATSOEVER, AND CLIENT’S MAXIMUM REMEDY, REGARDLESS OF THE FORM OF ACTION, WHETHER IN CONTRACT, TORT OR OTHERWISE, SHALL BE LIMITED TO THE NET PROFIT OF DESIGNER. IN NO EVENT SHALL DESIGNER BE LIABLE FOR ANY LOST DATA OR CONTENT, LOST PROFITS, BUSINESS INTERRUPTION OR FOR ANY INDIRECT, INCIDENTAL, SPECIAL, CONSEQUENTIAL, EXEMPLARY OR PUNITIVE DAMAGES ARISING OUT OF OR RELATING TO THE MATERIALS OR THE SERVICES PROVIDED BY DESIGNER, EVEN IF DESIGNER HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES, AND NOTWITHSTANDING THE FAILURE OF ESSENTIAL PURPOSE OF ANY LIMITED REMEDY.
RIGHTS TO FINAL ART
License: Designer grants to Client a non-exclusive, perpetual and worldwide license to use and display the Final Deliverables in accordance with this Agreement. The rights granted to Client are for use of the Final Deliverables in its original form only. Client may not change, create derivative works or extract portions of the Final Deliverables.
Liquidation for unlicensed use: Additional use of any Deliverables by Client outside the scope of the license granted above requires additional fees. Designer shall be entitled to further compensation equal to 100% percent of the total original Project fee unless otherwise agreed in writing by both parties. In the event of non-payment, Designer shall be entitled to pursue all remedies under law and equity.
RIGHTS TO DELIVERABLES OTHER THAN FINAL ART
Client Content: Client Content is the exclusive property of the Client. Client grants Designer a nonexclusive, nontransferable license to use, reproduce, modify, display and publish the Client Content solely in connection with Designer’s performance of the Services and limited promotional uses of the Deliverables as authorized in this Agreement.
Preliminary Works: Designer retains all rights in and to all Preliminary Works. Client shall return all Preliminary Works to Designer within thirty (30) days of completion of the Services.
Designer Tools: All Designer Tools are and shall remain the exclusive property of Designer. Designer grants Client a nonexclusive, nontransferable, perpetual, worldwide license to use the Designer Tools solely to the extent necessary with the Final Deliverables for the Project.
The Client retains the copyright to data, files and graphic logos provided by the Client, and grants GM Creative Art the rights to publish and use such material. The Client must obtain permission and rights to use any information or files that are copyrighted by a third party. The Client is further responsible for granting GM Creative Art permission and rights for use of the same and agrees to indemnify and hold harmless GM Creative Art from any and all claims resulting from the Client's negligence or inability to obtain proper copyright permissions. A contract for website design and/or placement shall be regarded as a guarantee by the Client to GM Creative Art that all such permissions and authorities have been obtained. Evidence of permissions and authorities may be requested.
Warranty Period: During the first 1 month following expiration of this Agreement, Designer shall provide up to 3 hours of Support Services at no additional cost to Client. Support Services means commercially reasonable technical support and assistance to maintain and update the Deliverables, including correcting any errors or Deficiencies. Requests for additional support will be billed on a time and materials basis at Designers standard rate.
Maintenance Period: After the Warranty Period expires and at Client’s option, Designer will provide Support Services for the following 3 months for Designer’s hourly fees of 60 EUR per hour.
No Enhancements: The services in the Warranty Period and the Maintenance Period do not include enhancements to the Project or other services outside the scope of the Proposal.
Designer shall not be liable for any loss or damage which Client may suffer which is in any way attributable to any delay in performance or completion of our contract, however that delay arises.
If the Client's website is to be installed on a third-party server, GM Creative Art must be granted temporary read/write access to the Client's storage directories which must be accessible via FTP. Depending on the specific nature of the project, other resources might also need to be configured on the server, which may involve additional costs for Client.
GM Creative Art makes every effort to ensure websites are designed to be viewed by the majority of visitors. Websites are designed to work with the most popular current browsers (e.g. Firefox, Internet Explorer 8 & 9, Google Chrome, etc.). Client agrees that GM Creative Art cannot guarantee correct functionality with all browser software across different operating systems.
GM Creative Art cannot accept responsibility for web pages which do not display acceptably in new versions of browsers released after the website have been designed and handed over to the Client. As such, GM Creative Art reserves the right to quote for any work involved in changing the website design or website code for it to work with updated browser software.
CROSS BROWSER COMPATIBILITY
By using current versions of well supported content management systems such as “Wordpress”, we endeavour to ensure that the web sites we create are compatible with all current modern web browsers such as the most recent versions of Internet Explorer, Firefox, Google Chrome and Safari. Third party extensions, where used, may not have the same level of support for all browsers. Where appropriate we will substitute alternative extensions or implement other solutions, on a best effort basis, where any incompatibilities are found.
Client is responsible for maintaining its own backups with respect to its website and we will not be liable for restoring any client data or client websites except to the extent that such data loss arises out of a negligent act or omission by us.
Designer does not guarantee any specific position in search engine results for Clients website. We perform basic search engine optimization (unless otherwise agreed with Client) according to current best practices.
Client is responsible for complying with all relevant laws relating to e-commerce, and to the full extent permitted by law will hold harmless, protect, and defend and indemnify GM Creative Art and its subcontractors from any claim, penalty, tax, tariff loss or damage arising from your or your clients’ use of Internet electronic commerce.
GM Creative Art may purchase domain names on behalf of the Client. Payment and renewal of those domain names is the responsibility of the Client. The loss, cancellation or otherwise of the domain brought about by non or late payment is not the responsibility of GM Creative Art. The Client should keep a record of the due dates for payment to ensure that payment is received in good time.
During the Maintenance Period, Client may request that Designer develop enhancements to the Deliverables. Designer shall exercise commercially reasonable efforts to prioritize Designer’s resources to create such enhancements. Client understands Designer may have preexisting obligations that may delay requested enhancements. Designer shall provide any enhancements shall be provided on a time and materials basis at the Designers standard rate.
Alterations: Alteration of any Deliverable is prohibited without the express permission of Designer. Designer will be given the first opportunity to make the required alterations. Unauthorized alterations shall constitute additional use and will be billed accordingly.
The agreement constituted by these terms and conditions and any proposal will be construed according to and is governed by the laws of Romania. Client and GM Creative Art submit to the non-exclusive jurisdiction of the courts in and of Romania in relation to any dispute arising under these terms and conditions or in relation to any services we perform for you.
GM Creative Art hereby excludes itself, its Employees and or Agents from all and any liability from:
- Loss or damage caused by any inaccuracy;
- Loss or damage caused by omission;
- Loss or damage caused by delay or error, whether the result of negligence or other cause in the production of the web site;
- Loss or damage to clients' artwork/photos, supplied for the site. Immaterial whether the loss or damage results from negligence or otherwise.
The entire liability of GM Creative Art to the Client in respect of any claim whatsoever or breach of this Agreement, whether or not arising out of negligence, shall be limited to the charges paid for the Services under this Agreement in respect of which the breach has arisen.
In the event any one or more of the provisions of this Agreement shall be held to be invalid, illegal or unenforceable, the remaining provisions of this Agreement shall be unimpaired and the Agreement shall not be void for this reason alone. Such invalid, illegal or unenforceable provision shall be replaced by a mutually acceptable valid, legal and enforceable provision, which comes closest to the intention of the parties underlying the invalid.
Negotiation: Parties agree to attempt to resolve any dispute by negotiation between the parties.
Arbitration/Mediation: If parties are unable to resolve the dispute by negotiation, either party may start mediation and/or binding arbitration in a forum mutually agreed to by the parties.
Litigation: In all other circumstances, the parties specifically consent to the local, state and federal courts located in the state of Romania. The parties waive any jurisdictional or venue defenses available to them and further consent to service of process by e-mail.
Attorney Fees: The prevailing party shall be entitled to recover its attorneys’ fees and costs in any dispute resolved by binding arbitration or litigation.
Clients who experience a problem with their web service provided by GM Creative Art should raise the matter directly using our online contact form to do so, giving sufficient information to locate the material (such as an url), printscreens or other materials and clearly outlining the grounds for complaint.
GM Creative Art will approach the individual responsible for the material in question with a view to resolving the matter to the satisfaction of the complainant.
FORMAL COMPLAINTS PROCEDURE
The formal complaints procedure should only be used where the complainant feels that the nature of the complaint is too serious to be dealt with informally, or where a satisfactory conclusion has not been reached after following the informal procedure.
A formal complaint should be made in writing to GM Creative Art, who will acknowledge receipt and ensure that the matter is looked into as soon as possible.
An initial response to any complaint can be expected within seven (7) days of its receipt; a full and considered response to the complaint should be completed within thirty (30) days and any subsequent remedy implemented with the minimum of delay.
TERM AND TERMINATION
Term: This agreement shall begin when both parties sign and shall continue until all Services are complete and delivered, or until the Agreement is Terminated.
Termination for Cause: Either party may terminate this agreement at any time, on 14 days prior written notice if the other party breaches any of its material responsibilities or obligations under this Agreement and fails to cure that breach during that 14 day period.
Termination for Insolvency: Either party may terminate this agreement at any time, on written notice to the other party, if the other party ceases to conduct business in its normal course; makes an assignment for the benefit of creditors; is liquidated or otherwise dissolved; becomes insolvent; files a petition in bankruptcy; or a receiver, trustee, or custodian is appointed for it.
Termination by Mutual Agreement: This agreement my be terminated by the mutual agreement of the parties.
Termination for Convenience: Either party may terminate this agreement at any time and for any reason on 21 days prior written notice to the other party. If Client terminates the Agreement under this section, Designer shall, at Clients reasonable discretion, complete any work assigned or scheduled during the notice period in accordance with the terms and conditions of this Agreement.
Termination Fees: In the event of termination, Client shall pay Designer for the Services performed through the date of termination in the amount of a prorated portion of the fees due.
Client shall pay all Expenses, Fees, and Additional Costs incurred through the date of termination.
Intellectual Property: If Client terminates and on full payment of compensation, Designer grants Client right and title as provided by this Agreement with respect to those Deliverables provided and accepted by Client as of the date of termination.
Confidential Information: On expiration or termination of this Agreement: (a) each party shall return or, at the disclosing party’s request, destroy the Confidential Information of the other party, and (b) all rights and obligations regarding Confidential Information shall survive.
Modification/Waiver: Modifications to this Agreement must be in writing and signed by both parties. Failure by either party to enforce any right or seek to remedy any breach under this Agreement shall not be construed as a waiver of such rights nor shall a waiver by either party of default in one or more instances be construed as constituting a continuing waiver or as a waiver of any other breach.
Notices. All notices under this Agreement shall be given in writing either by: (a) Fax or Email, with return confirmation of receipt; (b) Certified or Registered mail, with return receipt requested. Notice will be effective when received, or in the case of email or fax, on confirmation of receipt.
No Assignment. Rights or obligations under this Agreement shall not be transferred, assigned or encumbered without the prior written consent of the other party.
Governing Law. This Agreement shall be governed by the law of Romania.
Severability: If any provision of this Agreement is held invalid or unenforceable, the remainder of this Agreement shall remain in full force and effect. Where possible the invalid or unenforceable provision shall be interpreted in such manner as to be effective and valid under applicable law.
Headings: Headings and numbering used in this Agreement are for convenience and reference only and shall not affect the scope, meaning, intent or interpretation of this Agreement, and shall not have any legal effect.
Complete Agreement: This Agreement is the entire understanding of the parties and supersedes all prior understandings and documents relating to the subject matter of this Agreement.